As prescribed in 3442.7003, insert the following clause in all solicitations and contracts other than purchase orders:
NOTICE TO THE GOVERNMENT OF DELAYS (AUG 1987)
Whenever the contractor has knowledge that any actual or potential situation, including but not limited to labor disputes, is delaying or threatens to delay the timely performance of work under this contract, the contractor shall immediately give written notice thereof, including all relevant information with respect thereto, to the contracting officer.
(End of clause)
