(a) When the DFARS Clause 252.217-7028, Over and Above Work, is prescribed in solicitations and contracts, include the clause at 5352.291-9000, Additional Over and Above Work Procedures, in Section I.
(b) If the contract contains both over and above work procedures and Government-furnished material, the contracting officer shall insert the clause at 5352.291-9001, Excess Inventory-Disposition of Government Property, in Section I.
(c) When contractors performing maintenance, repair, overhaul, and modification on Air Force equipment in overseas locations are unable to obtain replacement parts through purchase in local markets, the contracting officer shall insert the clause at 5352.291-9003, Maintenance of Government-Owned Equipment in Possession of Overseas Contractors, in Section I. Use of this clause is required for Depot Maintenance Activity Group (DMAG) contracts containing a requirement for a GFM report (GFM reporting may be by the manual report on AF Form 412 (Report of Government Furnished Material), the mechanized GFM Transaction Reporting System (G009), or Commercial Asset Visibility II (CAV II).
(d) When the Statement of Objectives, SOW or purchase request require drop-in maintenance, use the clause at 5352.291-9004, Drop-In Maintenance, in Section I of aircraft PDM contracts. Establish an over and above line item to facilitate this work.
(e) The contracting officer shall insert the clause at 5352.291-9005, End Items Beyond Economical Repair, in Section I when the contract calls for repair of exchangeable assets.
(f) When appropriate to delay input of aircraft because output of aircraft is delayed, the contracting officer may insert the clause at 5352.291-9006, Delay of Aircraft Input, Section F.
(g) The contracting officer may insert the clause at 5352.291-9011, Induction at Risk, when Performance Based Delivery on Demand Contracts will be used.
