As prescribed in 5345.306-5(90), insert the following clause, substantially as written, in Section I:
GOVERNMENT-FURNISHED TOOLING (AFMC) (JUL 1997)
(a) Pursuant to the Government property clause herein, the Government shall furnish the tooling as set forth in the tooling/test equipment list attached and/or listed below to the Contractor for use in the performance of the contract. If any tooling is identified as master tooling it must be used in the manufacture of the item(s) in this solicitation or contract. By submission of a bid/offer, the Contractor certifies that the master tooling listed herein will be used to manufacture the item(s) designated in the tooling/test equipment list.
(b) Requisitioning documentation for the tooling shall be prepared by the Government. The tools shall be shipped to the successful offeror at the Government’s expense.
(c) If FAR 52.245-19, Government Property Furnished “As Is”, is included in this contract, it does not apply to any master tooling provided.
(d) The Contractor shall notify the Contracting Officer if the listed tooling is not received within (insert days) after award. Day for day adjustments to the contract delivery schedule shall be made for late delivery of the tooling, provided the Government receives notification within 5 days after the due date. Failure to notify the Government within 5 days after nonreceipt of the tooling constitutes waiver of a claim for contract delivery date or price adjustment resulting from the late notification to the Government. However, further Government delays after notification may be subject to delivery date or price adjustment.
(e) The Contractor shall request tooling disposition instructions in writing from the Contracting Officer when the tooling is no longer needed but not later than 60 days after the last item on the contract has been shipped. A copy of the request shall be provided to: (insert name of System Program Office or System Program Director).
The request for disposition instructions must include:
(1) List of tools by tool number.
(2) The part number of the item on which the tools are used.
(3) Contract number under which the tools were used.
(4) The date by which the tools could be ready to ship.
(5) Any related packing, crating, or handling costs proposed for the service.
(f) Tooling/Test Equipment List:
CLIN TOOL ID TOOL CODE MPN QTY MASTER (Y/N)
(End of clause)
