As prescribed in 3427.471, insert the following clause in all solicitations and contracts:
PAPERWORK REDUCTION ACT (AUG 1987)
(a) The Paperwork Reduction Act of 1980 (Pub. L. 96-511) applies to contractors that collect information for use or disclosure by the Federal Government.
If the contractor will collect information requiring answers to identical questions from 10 or more people then no plan, questionnaire, interview guide, or other similar device for collecting information may be used without first obtaining clearance from the Deputy Under Secretary for Management (DUSM) or his/her delegate within the Department of Education (ED) and the Office of Management and Budget (OMB). Contractors and Contracting Officers' Technical Representatives shall be guided by the provisions of 5 CFR Part 1320, Controlling Paperwork Burdens on the Public, and seek the advice of the Department's Paperwork Clearance Officer to determine the procedures for acquiring DUSM and OMB clearance.
(b) The contractor shall obtain the required DUSM and OMB clearance through the Contracting Officer's Technical Representative before expending any funds or making public contacts for the collection of information described in (a) above. The authority to expend funds and proceed with the collection shall be in writing by the contracting officer. The contractor must plan at least 120 days for DUSM and OMB clearance. Excessive delay caused by the Government which arises out of causes beyond the control and without the fault or negligence of the contractor will be considered in accordance with the Excusable Delays or Default clause of this contract.
(End of clause)
